Intec Microsystems Ltd Terms of Purchase
1. INTERPRETATION
1.1 Definitions:
The following definitions are used in these Conditions:
"Business Day": a day other than a Saturday, Sunday or a public or bank holiday in England.
"Business Hours": the period from 9.00 am to 5.00 pm on any Business Day.
"Conditions": the terms and conditions set out in this document as amended from time to time in accordance with clause 14.4.
"Contract": the contract between the Customer and the Supplier for the sale and purchase of the Goods in accordance with these Conditions.
"Customer": Intec Microsystems Ltd (a company registered in England and Wales with company number 04933374).
"Delivery Date": the date specified in the Order, or, otherwise agreed by the Customer in writing or if none is so specified or agreed, within 30 days of the date of the Order.
"Delivery Location": the address for delivery of Goods as set out in the Order.
"Goods": the goods (or any part of them) set out in the Order.
"Mandatory Policies": the Customer's business policies and codes as published on our website https://intecmicros.co.uk including our Modern Slavery and Human Trafficking Policy (MSHT) and (where applicable) Ubiquiti Control Compliance with the United States Export Control and Trade and Economic Sanctions Regulations,.
"Order": the Customer's order for the Goods, as set out in the Customer's purchase order or in the Customer's written acceptance of the Supplier's quotation as the case may be.
"Specification": any specification for the Goods, including any related plans and drawings, that is agreed in writing by the Customer and the Supplier.
"Supplier": the person or firm from whom the Customer purchases the Goods.
1.2 Interpretation:
(a) A person includes a natural person, corporate or unincorporated body (whether or not having separate legal personality).
(b) A reference to a party includes its successors and permitted assigns.
(c) A reference to legislation or a legislative provision is a reference to it as amended or re-enacted. A reference to legislation or a legislative provision includes all subordinate legislation made under that legislation or legislative provision.
(d) Any words following the terms including, include, in particular, for example or any similar expression shall be interpreted as illustrative and shall not limit the sense of the words preceding those terms.
(e) A reference to writing or written excludes fax but not email.
2. BASIS OF CONTRACT
2.1 These Conditions apply to the Contract to the exclusion of any other terms that the Supplier seeks to impose or incorporate, or which are implied by law, trade custom, practice or course of dealing.
2.2 The Order constitutes an offer by the Customer to purchase the Goods in accordance with these Conditions.
2.3 The Order shall be deemed to be accepted on the earlier of:
(a) the Supplier issuing a written acceptance of the Order; and
(b) the Supplier doing any act consistent with fulfilling the Order,
at which point the Contract shall come into existence.
2.4 The Supplier waives any right it might otherwise have to rely on any term endorsed upon, delivered with or contained in any documents of the Supplier that is inconsistent with these Conditions.
3. THE GOODS
3.1 The Supplier shall ensure that the Goods shall:
(a) correspond with their description and any applicable Specification;
(b) be of satisfactory quality (within the meaning of the Sale of Goods Act 1979) and fit for any purpose held out by the Supplier or made known to the Supplier by the Customer expressly or by implication, and in this respect the Customer relies on the Supplier's skill and judgement;
(c) where they are manufactured products, be free from defects in design, material and workmanship and remain so for the warranty period provided by the manufacturer or supplier of the products or the period of 12 months following the date of delivery to the Customer (whichever is of the longer duration); and
(d) comply with all applicable statutory and regulatory requirements relating to the manufacture, labelling, packaging, storage, handling and delivery of the Goods.
3.2 The Supplier shall ensure that at all times it has and maintains all the licences, permissions, authorisations, consents and permits that it needs to carry out its obligations under the Contract.
3.3 The Customer may inspect and test the Goods at any time before delivery. The Supplier shall remain fully responsible for the Goods despite any such inspection or testing and any such inspection or testing shall not reduce or otherwise affect the Supplier's obligations under the Contract.
3.4 If following such inspection or testing the Customer considers that the Goods do not conform or are unlikely to comply with the Supplier's undertakings at clause 3.1, the Customer shall inform the Supplier and the Supplier shall immediately take such remedial action as is necessary to ensure compliance.
3.5 The Customer may conduct further inspections and tests after the Supplier has carried out its remedial actions.
4. DELIVERY
4.1 The Supplier shall ensure that:
(a) the Goods are properly packed and secured in such manner as to enable them to reach their destination in good condition;
(b) each delivery of the Goods is accompanied by a delivery note which shows the date of the Order, the Order number (if any), the type and quantity of the Goods (including the code number of the Goods, where applicable), special storage instructions (if any) and, if the Goods are being delivered by instalments, the outstanding balance of Goods remaining to be delivered; and
(c) if the Supplier requires the Customer to return any packaging material to the Supplier, that fact is clearly stated on the delivery note. Any such packaging material shall be returned to the Supplier at the cost of the Supplier.
4.2 The Supplier shall deliver the Goods:
(a) on the Delivery Date or, if agreed by the Customer, before the Delivery Date;
(b) at the Delivery Location; and
(c) during the Customer's normal Business Hours, or as instructed by the Customer.
4.3 Delivery of the Goods shall be completed on the completion of unloading the Goods at the Delivery Location.
4.4 If the Supplier:
(a) delivers less than 90% of the quantity of Goods ordered, the Customer may reject the Goods; or
(b) delivers more than 105% of the quantity of Goods ordered, the Customer may at its discretion reject the excess Goods and any such rejected Goods shall be returnable at the Supplier's risk and expense.
If the Supplier delivers more or less than the quantity of Goods ordered, and the Customer accepts the delivery, a pro rata adjustment shall be made to the invoice for the Goods.
4.5 The Supplier shall not deliver the Goods in instalments without the Customer's prior written consent. Where it is agreed that the Goods are to be delivered by instalments, they may be invoiced and paid for separately. However, failure by the Supplier to deliver any one instalment on time or at all, or any defect in an instalment shall entitle the Customer to the remedies set out in clause 5.
5. CUSTOMER REMEDIES
5.1 If the Goods are not delivered on the Delivery Date, or do not comply with the undertakings set out in clause 3.1, then, without limiting any of its other rights or remedies, and whether or not it has accepted the Goods, the Customer may exercise any one or more of the following rights and remedies:
(a) to terminate the Contract;
(b) to reject the Goods (in whole or in part) and return them to the Supplier at the Supplier's own risk and expense;
(c) to require the Supplier to repair or replace the rejected Goods, or to provide a full refund of the price of the rejected Goods (if paid);
(d) to refuse to accept any subsequent delivery of the Goods which the Supplier attempts to make;
(e) to recover from the Supplier any costs incurred by the Customer in obtaining substitute goods from a third party; and
(f) to claim damages for any other costs, loss or expenses incurred by the Customer which are in any way attributable to the Supplier's failure to carry out its obligations under the Contract.
5.2 These Conditions shall apply to any repaired or replacement Goods supplied by the Supplier.
5.3 The Customer's rights and remedies under these Conditions are in addition to its rights and remedies implied by statute and common law.
6. TITLE AND RISK
Title and risk in the Goods shall pass to the Customer on completion of delivery.
7. PRICE AND PAYMENT
7.1 The price of the Goods shall be the price set out in the Order, or, if no price is quoted, the price set out in the Supplier's published price list in force as at the date the Contract came into existence.
7.2 The price of the Goods:
(a) shall specify whether value added tax (VAT) is included or not included and if it does not do so the price shall be inclusive of VAT, which the Customer shall additionally be liable to pay to the Supplier at the prevailing rate, subject to the receipt of a valid VAT invoice; and
(b) includes the costs of packaging, insurance and carriage of the Goods to the Delivery Location unless otherwise set out in the Order or expressly agreed by the Customer in writing by reference to Incoterms® 2020.
7.3 No extra charges shall be effective unless agreed in writing with the Customer.
7.4 The Supplier may invoice the Customer for price of the Goods plus VAT at the prevailing rate (if applicable) on or at any time after the completion of delivery. The Supplier shall ensure that the invoice includes the date of the Order, the invoice number, the Customer's order number, the Supplier's VAT registration number and any supporting documents that the Customer may reasonably require.
7.5 Unless otherwise set out in the Order or expressly agreed by the Customer in writing, the Customer shall pay correctly rendered invoices within 30 days following the end of the month in which the invoice is received by the Customer. Payment shall be made to the bank account nominated in writing by the Supplier or if none is so specified by such other means as are set out in the Order or otherwise agreed by the Customer in writing.
7.6 Unless otherwise set out in the Order or agreed by the Customer in writing, the currency for payment shall be pounds sterling.
7.7 If a party fails to make any payment due to the other party under the Contract by the due date for payment, then the defaulting party shall pay interest on the overdue sum from the due date until payment of the overdue sum, whether before or after judgment. Interest under this clause will accrue each date at 2% a year, Where a payment is disputed in good faith, interest is only payable after the dispute is resolved, on sums found or agreed to be due, from 5 days after the dispute is resolved until payment.
7.8 The Customer may at any time set off any liability of the Supplier to the Customer against any liability of the Customer to the Supplier whether or not that liability arises under the Contract. If the liabilities to be set off are expressed in different currencies, the Customer may convert either liability at a market rate of exchange for the purpose of set-off. Any exercise by the Customer of its rights under this clause shall not limit or affect any other rights or remedies available to it under the Contract or otherwise.
8. INDEMNITY
8.1 The Supplier shall indemnify the Customer against all liabilities, costs, expenses, damages and losses (including but not limited to any direct, indirect or consequential losses, loss of profit, loss of reputation and all interest, penalties and legal costs (calculated on a full indemnity basis) and all other reasonable professional costs and expenses) suffered or incurred by the Customer as a result of or in connection with:
(a) any claim made against the Customer for actual or alleged infringement of a third party's intellectual property rights arising out of or in connection with the manufacture, supply or use of the Goods, to the extent that the claim is attributable to the acts or omissions of the Supplier, its employees, agents or subcontractors;
(b) any claim made against the Customer by a third party for death, personal injury or damage to property arising out of or in connection with defects in Goods, to the extent that the defects in the Goods are attributable to the acts or omissions of the Supplier, its employees, agents or subcontractors; and
(c) any claim made against the Customer by a third party arising out of or in connection with the supply of the Goods, to the extent that such claim arises out of the breach, negligent performance or failure or delay in performance of the Contract by the Supplier, its employees, agents or subcontractors.
8.2 This clause 8 shall survive termination of the Contract.
9. INSURANCE
During the term of the Contract and for a period of three years thereafter, the Supplier shall maintain in force, with a reputable insurance company, professional indemnity insurance, product liability insurance and public liability insurance to cover the liabilities that may arise under or in connection with the Contract, and shall, on the Customer's request, produce both the insurance certificate giving details of cover and the receipt for the current year's premium in respect of each insurance.
10. CONFIDENTIALITY
10.1 The Supplier undertakes that it shall not for a period of two years following the date of the Contract, disclose to any person any confidential information concerning the business, assets, affairs, customers, clients or suppliers of the other party, except as permitted by clause 10.2.
10.2 The Supplier may disclose the Customer’s confidential information:
(a) to its employees, officers, representatives, contractors, subcontractors or advisers who need to know such information for the purposes of exercising the Supplier's rights or carrying out the Supplier’s obligations under the Contract. provided that prior to making such disclosure the Supplier shall ensure that its employees, officers, representatives, contractors, subcontractors or advisers to whom it discloses the Customer's confidential information comply with this clause 10; and
(b) as may be required by law, a court of competent jurisdiction or any governmental or regulatory authority.
10.3 The Supplier shall use the customer’s confidential information for any purpose other than to exercise its rights and perform its obligations under or in connection with the Contract.
11. COMPLIANCE WITH RELEVANT LAWS AND POLICIES
11.1 In performing its obligations under the Contract, the Supplier shall:
(a) comply with all applicable laws, statutes, regulations and codes from time to time in force; and
(b) comply with the Mandatory Policies.
11.2 The Customer may immediately terminate the Contract for any breach of clause 11.1.
12. TERMINATION
12.1 The Customer may terminate the Contract in whole or in part at any time before delivery of the Goods with immediate effect by giving the Supplier written notice, whereupon the Supplier shall discontinue all work on the Contract. The Customer shall pay the Supplier fair and reasonable compensation for any work in progress on the Goods at the time of termination, but such compensation shall not include loss of anticipated profits or any consequential loss.
12.2 Without limiting its other rights or remedies, the Customer may terminate the Contract with immediate effect by giving written notice to the Supplier if:
(a) the Supplier commits a material breach of any term of the Contract and (if such a breach is remediable) fails to remedy that breach within 30 days of the Supplier being notified in writing to do so;
(b) the Supplier takes any step or action in connection with its entering administration, provisional liquidation or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), obtaining a moratorium, being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business or, if the step or action is taken in another jurisdiction, in connection with any analogous procedure in the relevant jurisdiction;
(c) the Supplier takes any step or action in connection with the Supplier being insolvent, entering any composition or arrangement with its creditors, having a receiver appointed to any of its assets, or ceasing to carry on business or if the step or action is taken in another jurisdiction, in connection with any analogous procedure in the relevant jurisdiction;
(d) the Supplier suspends, or threatens to suspend, or ceases or threatens to cease to carry on all or a substantial part of its business; or
(e) the Supplier's financial position deteriorates so far as to reasonably justify the opinion that its ability to give effect to the terms of the Contract is in jeopardy.
12.3 Termination of the Contract, however arising, shall not affect any of the parties' rights and remedies that have accrued as at termination, including the right to claim damages in respect of any breach of the Contract which existed at or before the date of termination.
12.4 Any provision of the Contract that expressly or by implication is intended to come into or continue in force on or after termination of the Contract shall remain in full force and effect.
13. FORCE MAJEURE
Neither party shall be in breach of the Contract or otherwise liable for any failure or delay in the performance of its obligations if such delay or failure results from events, circumstances or causes beyond its reasonable control. The time for performance of such obligations shall be extended accordingly. If the period of delay or non-performance continues for six weeks, the party not affected may terminate the Contract by giving 30 days' written notice to the affected party.
14. GENERAL
14.1 Assignment and other dealings
(a) The Customer may at any time assign, transfer, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any or all of its rights or obligations under the Contract.
(b) The Supplier may not assign, transfer, mortgage, charge, delegate, declare a trust over or deal in any other manner with any or all of its rights or obligations under the Contract without the prior written consent of the Customer.
14.2 Subcontracting. The Supplier may not subcontract any or all of its rights or obligations under the Contract without the prior written consent of the Customer. If the Customer consents to any subcontracting by the Supplier, the Supplier shall remain responsible for all the acts and omissions of its subcontractors as if they were its own.
14.3 Entire agreement.
(a) The Contract constitutes the entire agreement between the parties.
(b) Each party acknowledges that in entering into the Contract it does not rely on any statement, representation, assurance or warranty (whether made innocently or negligently) that is not set out in the Contract. Each party agrees that it shall have no claim for innocent or negligent misrepresentation based on any statement in the Contract.
14.4 Variation. Except as set out in these Conditions, no variation of the Contract, including the introduction of any additional terms and conditions, shall be effective unless it is agreed in writing and signed by the Customer.
14.5 Waiver.
(a) Except as set out in clause 2.4,a waiver of any right or remedy is only effective if given in writing and shall not be deemed a waiver of any subsequent right or remedy.
(b) A delay or failure to exercise, or the single or partial exercise of, any right or remedy shall not waive that or any other right or remedy, nor shall it prevent or restrict the further exercise of that or any other right or remedy.
14.6 Severance. If any provision or part-provision of the Contract is or becomes invalid, illegal or unenforceable, it shall be deemed deleted, but that shall not affect the validity and enforceability of the rest of the Contract. If any provision of the Contract is deemed deleted under this clause 14.6 the parties shall negotiate in good faith to agree a replacement provision that, to the greatest extent possible, achieves the intended commercial result of the original provision.
14.7 Notices.
(a) Any notice given to a party under or in connection with the Contract shall be in writing and shall be:
(i) delivered by hand or by pre-paid first-class post or other next working day delivery service at its registered office (if a company) or its principal place of business (in any other case); or
(ii) sent by email to any email address of any person or persons notified expressly or impliedly by the party for such purpose or if no such email address is so notified to an email address of any person or persons of the party dealing with the Contract on behalf of the party.
(b) Any notice shall be deemed to have been received:
(i) if delivered by hand, at the time the notice is left at the proper address;
(ii) if sent by pre-paid first-class post or other next working day delivery service, at 9.00 am in the place of receipt on the fourth Business Day after posting; or
(iii) if sent by email, at the time of transmission, or, if this time falls outside Business Hours in the place of receipt, when Business Hours resume.
(c) This clause does not apply to the service of any proceedings or other documents in any legal action or, where applicable, any arbitration or other method of dispute resolution.
14.8 Third party rights.
(a) The Contract does not give rise to any rights under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of the Contract.
(b) The rights of the parties to rescind or vary the Contract are not subject to the consent of any other person.
14.9 Governing law. The Contract, and any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with it or its subject matter or formation, shall be governed by and construed in accordance with the law of England and Wales.
14.10 Jurisdiction. Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.